Your local Gold Coast one stop shop for leaking shower / balcony repairs to full tiling requirements.
Your local Gold Coast one stop shop for leaking shower / balcony repairs to full tiling requirements.
An Industry Leading Warranty
All our workmanship comes with a (12) year warranty.
Every Davco product used by Totally Sealed is the result of a finely tuned process. From initial concept, through to research and development, to the highest manufacturing standards and rigorous performance testing, our products achieve and exceed market standards.
We know that the Davco range of primers, waterproofing membranes, adhesives, grouts and sealants will satisfy or surpass our customers’ needs for quality, safety and performance.
We are so confident that we guarantee our products will perform to their product specification for a period of at least ten (10) years* from date of manufacture.
* The only exception is Davco Rejuvenation Grout that carries a one (1) year performance guarantee
A Commitment to Sustainability
We at Totally Sealed, have a dual focus in our business decisions: what is good for the company and what contributes to the greater good of the communities within which we live and work.
Sustainability is at the heart of how Totally Sealed does business. We believe passionately in doing things the right way to achieve our success. We are committed to continually improving our sustainability performance and finding better ways to deliver our products and solutions whilst conserving natural resources.
Totally Sealed takes an integrated approach to sustainability with our initiatives pillared by our 4 commitments:
- Innovate to foster sustainable development
- Reduce the environmental footprint throughout our products’ lifecycle
- Act for and with our employees
- Anchor our facilities in local communities
A Responsibility to the Environment
At Totally Sealed we have a proud history of saying ‘no’. No to hazardous formulations that threaten our customers whilst they work and no to outdated technologies that pollute our world. We have long been aware that we have a responsibility to the environment and we must do all that we can as a business to protect it.
Our comprehensive approach to reducing our environmental impact means looking at all aspects of our business and continually assessing, monitoring and improving our environmental performance. Some of our environmental initiatives include:
- Using 100% recycled tyres in our rubber crumb adhesives, which assists in dramatically reducing one of the world’s largest waste disposal problems
- Assessing alternative local raw materials to help minimise shipping
- Treating 100% of waste water in our facilities on site
- Educating customers and the public as to the safe disposal of products and packaging
As a signatory to the Australian Packaging Covenant, we are also committed to using sustainable, recoverable and recyclable packaging and engaging supply chain partners with the same commitment for a better environment.
A Cleaner, Safer and Healthier Adhesive Range – our Dust Less Technology
Davco’s patented, award winning Dust Less Technology is at the core of our sustainability initiatives. Launched in 2006, Dust Less Technology creates 80% less airborne dust than traditional tile adhesives and is specifically formulated for improved air quality, better working conditions, less mess and faster clean-up.
Dust Less Technology can reduce product and financial losses from dust emissions but most importantly, it creates a cleaner, safer and healthier environment for our factory employees and our customers.
Davco’s Dust Less adhesives join the other environmentally friendly products we’ve designed to create a better and safer environment without compromising on performance.
Terms & Conditions
TERMS & CONDITIONS – TOTALLY SEALED
“Act” means the relevant legislation for the State in which the work is to be performed;
“Authorised person” means the person or contractor directed by Totally Sealed to perform the work;
“Completion Date” means the date when Totally Sealed Bathrooms finishes the Work in accordance with this Contract;
“Contract” means the Quotation, Plan and the Terms and Conditions as set out below;
“Owner” means the person or entity entering into this Contract with Totally Sealed including the Owner’s executors, administrators, successors and permitted assigns;
“parties” means Totally Sealed and the Owner;
“Plan” means the diagram (if any) included with the Quotation in relation to the Work;
“Price” means the price for the Work as set out in this Contract;
“Product” means a product used by Totally Sealed in relation to the Work;
“Product Warranty” means any product warranty expressly provided by Totally Sealed as set out in this Contract including in the Quotation or at the top of any page of this Contract;
“Quotation” means the Quote that accompanies these Terms and Conditions;
“Representative” means any person authorised by Totally Sealed in connection with this Contract;
“Site” means the location where the Work will be carried out as set out in the Quotation;
“Statutory Warranties” means the warranties provided by Totally Sealed in accordance with clause 9;
“Variation” means Variation to the Work in accordance with clause 8;
“Work” means the Work to be carried out by Totally Sealed in accordance with this Contract.
1.1 In this Contract a reference to a clause means a clause of this Contract unless otherwise stated.
2. QUALITY OF CONSTRUCTION
2.1 All Work done under this Contract will comply with:
2.1.1 the Building Code of Australia to the extent required under the relevant State legislation.
2.1.2 All other relevant codes, standards and specifications that the Work is required to comply with under any law; and
2.1.3 The conditions of any relevant development consent or complying development certificate and any construction certificate.
2.2 Despite clause 2.1 the liability of Totally Sealed for failure to comply with the above work compliance clause is limited if the failure relates solely to a design or specification prepared by the Owner or on the Owner’s behalf or a design or specification required by the Owner if Totally Sealed has advised the Owner in writing that it contravenes clause
3. PLANS AND WORK
3.1 The Plan and specifications for work to be done under this Contract, including any variations are taken to form part of this Contract.
3.2 Before Totally Sealed starts the Work the Owner must notify Totally Sealed of any matters that may affect the ability of Totally Sealed to undertake the Work such as previous repair Work to the Site or any report being done from a third party in relation to the Site or the Work.
3.3 Totally Sealed will re-grout or resurface or use a sealer where required as part of the Work, which is included in the Price.
3.4 Prior to application of a Product the surface of the Work area needs to be prepared with a chemical tile and stone etchant which may change the appearance of the tiles in some instances.
3.5 The Owner acknowledges:
3.5.1 the possible change in tile appearance with the use of a Product; and
3.5.2 such change in appearance will not be regarded as a defect under this Contract or a breach of any warranty whether statutory or otherwise.
3.6 All areas where the Work will be performed must be kept dry 24 hours prior to and 24 hours after the Work is carried out.
3.7 If the Work relates to a shower, it must not be used for 24 hours prior to commencement of the Work.
4. PLUMBING AND PAINTING
4.1 The Price does not include the cost of plumbing whether to drainage or otherwise and the Owner must contact a plumber for any plumbing issues that may be associated with the Work.
4.2 Totally Sealed will not carry out any painting or decorating whatsoever in relation to the Work.
5. LATENT DEFECTS, MOVEMENT AND HEALTH AND SAFETY
5.1 Subject to the Statutory Warranties Totally Sealed shall not be liable for any damage to framework, structure or tiles, faults, defects, deterioration or wear and tear in relation to the Work that were not visible or apparent at the initial inspection on Site by Totally Sealed (“Latent Defects”) but have appeared and/or deteriorated since the date of the inspection.
5.2 If Totally Sealed needs to carry out any additional work arising from the Latent Defects Totally Sealed may increase the Quotation to take account of the additional work.
5.3 If the Work includes a balcony repair, subject to the Statutory Warranties, Totally Sealed will not be liable for any claim arising from the movement of the structure on which the Work is carried out.
5.4 Totally Sealed may, at its discretion, refuse to carry out the Work if the health and safety of any Representative is exposed on Site and will request the Owner to rectify the problem at the Owner’s cost before the Work can be carried out or continued.
6. PAYMENT BY THE OWNER
6.1 The Owner must pay the Price due to Totally Sealed on the Completion Date unless stated otherwise in the Quotation.
6.2 The Work will be regarded as complete when it is finished in accordance with this Contract, free of apparent defects and all rubbish and surplus material removed from the Site.
6.3 The Owner authorises Totally Sealed to deduct all monies due under this Contract from any funds held Totally Sealed or from the Owner’s credit card if applicable after the Work has been completed or any money is owing to Totally Sealed in accordance with this Contract.
6.4 If Totally Sealed agrees with the Owner in the Quotation to accept payment after the Completion Date the Owner shall pay Totally Sealed all monies due under this Contract within 30 days of the Completion Date (“Payment Period”).
6.5 If the Owner does not pay Totally Sealed all outstanding monies owing under this Contract within the Payment Period unless otherwise stated in the Quotation the Owner must pay Totally Sealed interest at rate equal to ten percent (10%) per annum on all monies owing to Totally Sealed from the end of the Payment Period until the date of actual payment.
7. TIME FOR COMPLETION
7.1 Subject to clause 7. Totally Sealed will complete the Work within a reasonable time.
7.2 Totally Sealed will be entitled to a reasonable extension of time in the event of delays to the work where the cause of the delay is beyond Totally Sealed control including but not limited to:
7.2.1 inclement weather that prevents Totally Sealed from proceeding with the Work;
7.2.2 the unavailability of materials for the Work;
7.2.3 industrial disputes;
7.2.4 Variations; or
7.2.5 Any other matter beyond the control of Totally Sealed.
7.3 Any rectification work carried out by Totally Sealed after the Completion Date shall not extend any warranty period set out in this Contract to the extent permissible by law.
8.1 The Work may be varied by agreement between the Owner and Totally Sealed.
8.2 Subject to clause
8.3 Any Variation required by either party must be made in writing to the other party (“Variation Request”). The Variation Request must include a full description of the proposed Variation.
8.3 If the Variation as set out in the Variation Request is agreed the Variation must:
8.3.1 be in writing;
8.3.2 set out the cost of the additional or omitted Work;
8.3.3 set out any change to the Completion Date;
8.3.4 be signed by the parties and dated.
8.4 The price of any extra Work under a variation will be added to the Price and the cost of any omitted Work under a variation will be deducted from the Price.
8.5 The Work, Products or materials required under this Contract may be varied due to such other matters as could not reasonably be foreseen by an experienced contractor for the completion of the Work at the date of this Contract.
9. STATUTORY WARRANTIES
9.1 If the Work is residential work under the relevant legislation Totally Sealed warrants that:
9.1.1. the Work will be performed in a proper and workmanlike manner and in accordance with the plans and specifications set out in this Contract;
9.1.2 all materials supplied by Totally Sealed will be good and suitable for the purpose for which they are used and, unless otherwise stated in this Contract , those materials will be new;
9.1.3. the Work will be done in accordance with, and will comply with, the relevant legislation or any other law;
9.1.4 the Work will be done with due diligence and within the time stipulated in this Contract, or if no time is stipulated, within a reasonable time;
9.1.5 If the Work consists of the making of alterations or additions to a dwelling or the repairing, renovation, decoration or protective treatment of a dwelling, the Work will result, to the extent of the Work conducted, in a dwelling that is reasonably fit for occupation as a dwelling;
9.1.6 the Work and any materials used in doing the Work will be reasonably fit for the specified purpose or result, if the Owner expressly makes known to Totally Sealed or any other person with express or apparent authority to enter into or vary contractual arrangements on behalf of Totally Sealed the particular purpose for which the Work is required or the result that the Owner desires the Work to achieve, so as to show that the Owner relies on Totally Sealed skill and judgment.
10.1 The Owner must provide access for any Representative to carry out the Work as required during Work hours allowed by relevant statutory authorities.
10.2 The Owner must remove any personal property likely to impede the Work.
10.3 Unless a minimum of 24 hours’ notice is given to Totally Sealed if a Representative cannot access the Site or is unable to proceed with the Work for any reason an additional call out charge at the prevailing rate will be payable by the Owner to Totally Sealed.
11. CLEANING UP
11.1 On completion of the Work, Totally Sealed must remove from the Site all of its tools and equipment and dispose of all rubbish, excavated material, vegetation, demolished or dismantled structures and surplus material relating to the Work.
11.2 All demolished, dismantled and surplus material will be the property of Totally Sealed unless otherwise specified in the Quotation.
12. INSURANCE FOR WORK AND PERSONAL INJURY
12.1 Totally Sealed maintains all compulsory insurances to cover its various liabilities prior to commencing any work under this Contract or is given access to the site.
12.1.1 If requested Totally Sealed must provide the Owner with proof that all such insurances have been taken out and are current;
12.1.2 Home warranty insurance to cover defective and incomplete Work if required under the relevant legislation. 12.2 Where required by law, Totally Sealed will obtain Home Warranty Insurance or equivalent cover for the work and provide a certificate copy to the Owner.
13. INDEMNITY IN FAVOUR OF OWNER
13.1 Subject to clause
13.2 Totally Sealed will indemnify the Owner against any loss or liability for death, personal injury or property damage arising out of the Work, except to the extent that the Owner or an employee, agent or subcontractor of the Owner contributed to the loss or liability.
13.3 Totally Sealed will not be liable under clause 13.1 if the death, personal injury, property damage was caused or contributed by a design or specification prepared by or on behalf of the Owner.
14. DAMAGE TO PROPERTY
14.1 The Owner must remove any furniture or personal goods from the Site and immediate vicinity to minimise the risk of damage.
14.2 Totally Sealed warrants that it will take all reasonable care when removing grout on floor and wall joints.
15.1 If the Owner or its employees, agents or contractors makes any misrepresentation to Totally Sealed that causes additional work, such additional Work will be a deemed Variation and added to the Price Totally Sealed may, at its discretion, refuse to carry out such additional Work.
16. PRODUCT WARRANTY
16.1. Totally Sealed – the products listed here against defects for the following periods:
- Silcone – 5 Years from the date of application or the completion of the works
- Davco Epoxy Grout – 10 Years from the date of application or the completion of the works
- Davco SMP EVO – – 10 Years from the date of application or the completion of the works
16.2. The benefits of this warranty are in addition to all other rights and remedies which the owner may have under these Terms, the Australian Consumer Law and any other law in relation to the product to which the warranty relates.
16.3. Totally Sealed products come with guarantees that cannot be excluded under the Australian Consumer Law. You are entitled to a replacement or refund for a major failure or for compensation for any other reasonably foreseeable loss or damage.
16.4. This warranty does not cover damage, fault or failure due to external causes, including accident, misuse, tampering or interference with the product other than by an authorised Totally Sealed representative, failure to perform required maintenance, normal wear and tear, fire, flood or a similar occurence and any attempt by any person other than an authorised Totally Sealed representative to adjust or repair the product.
16.5. In the event of a defects claim the owner must follow the claims procedure outlined at Clause 18 of these Terms & Conditions.
17. ENTIRE CONTRACT & REPRESENTATIONS
17.1 This entire contract together with any documents signed, dated and attached to it constitutes the entire contract between Totally Sealed and the Owner. It supersedes all previous understandings, agreements or representations between Totally Sealed and the Owner whether in writing or otherwise.
17.2 Totally Sealed and the Owner acknowledge that no other statements, representations, inducements, promises or agreements made orally or otherwise by either of them are to be relied upon or binding.
18. NOTICE OF CLAIM
18.1 The Owner must notify Totally Sealed Bathrooms in writing within 10 business days after becoming aware of any matter or circumstance that may give rise to a claim under this Contract and set out details of the claim (“Notice of Claim”).
18.2 If the Owner serves such a Notice Totally Sealed will within 14 days of receipt of the Notice respond to the Owner and request a date and time to inspect the Work on Site.
18.3 The Owner must allow Totally Sealed to rectify any defective Work that is capable of rectification and is required to be rectified under this Contract;
18.4 If Totally Sealed is required to carry out the rectification work Totally Sealed shall serve a further notice on the Owner within 14 days after the Site Inspection to nominate a mutually convenient date and time within 21 days of the Site Inspection for Totally Sealed to carry out the Rectification Work;
18.5 If Totally Sealed undertakes a Site Inspection and is not liable to rectify the alleged defective work set out in the Notice of Claim Totally Sealed shall be entitled to charge the Owner a call out fee for the Site Inspection at the prevailing rate at the time of the Site Inspection.
19. TERMINATION OF CONTRACT
19.1 If Totally Sealed:
19.1.1 goes into liquidation, administration or is otherwise without full capacity;
19.1.2 fails to complete the Work within a reasonable time;
19.1.3 fails to remedy defective Work or replace faulty or unsuitable materials or Products as provided in this Contract; or
19.1.4 otherwise breaches a term of this Contract The Owner may, where such default can be remedied, issue a written notice requiring Totally Sealed to remedy the default within 10 business days or within such other reasonable period as may be agreed.
19.2 If the default is not remedied within 10 business days or such other reasonable period as may be agreed, or is not capable of being remedied, the Owner may terminate this Contract by written notice to Totally Sealed.
19.3 If the Owner:
19.3.1 fails to make any payment due under this Contract; or
19.3.2 denies access to the Site to Totally Sealed to prevent the Work from proceeding; or
19.3.3 otherwise breaches a term of this Contract Totally Sealed may issue a written notice requiring the Owner to remedy the default within 10 business days of receipt of the notice by the Owner.
19.4 If the default is not remedied within 10 business days Totally Sealed may terminate this Contract by written notice to the Owner.
20.1 The Owner’s agent, employee or contractor who signs this Contract on behalf of the Owner (“Owner’s Signatory”) warrants that it, he or she has authority to enter into this Contract on behalf of the Owner.
20.2 The Owner’s Signatory will indemnify Totally Sealed against all loss or damages Totally Sealed may suffer arising from a breach of warranty set out in clause 20.1.
20.3 Any representative who signs this Contract on behalf of Totally Sealed (“Totally Sealed Signatory”) warrants that he or she has authority to enter into this Contract on behalf of Totally Sealed.
20.4 The Totally Sealed Signatory will indemnify the Owner against all loss or damages the Owner may suffer arising from a breach of warranty set out in clause 20.3.
21.1 If a party considers a dispute has arisen in relation to any matter covered by this Contract, that party must promptly give the other party written notice of the items of dispute.
21.2 The parties may confer with a mutually agreed third party to assist to resolve the dispute by mediation.
21.3 If applicable, the home warranty insurer should be notified of any dispute, which may be a prospective claim on the insurer.
22.1 Any written notice required to be given by this Contract or under the cooling off provision under the relevant legislation (if applicable) may be served by:
22.1.1 giving it to the party in person;
22.1.2 leaving it at the party’s address shown in this Contract; or
22.1.3 sending it by registered post to the party’s address shown in this Contract.
23.1 Any condition of this Contract which is illegal, void or rendered unenforceable shall be severed from this Contract so that the legality, validity or enforceability of the remaining provisions of this Contract shall not be affected.
24. GOVERNING LAW AND JURISDICTION
24.1 This Contract is governed by the laws of the State in which the Work is carried out by Totally Sealed.
24.2 Each party irrevocably submits to the jurisdiction of the courts of that State.
25. AUSTRALIAN CONSUMER LAW
25.1 Despite anything to the contrary in this Contract:
25.1.1 this Contract is subject to the provisions of the Australian Consumer Law and the Australian Consumer Law prevails to the extent of any inconsistency.